Causes, Effects, Benefits, and Remedies of Change Orders on Public Construction Projects in Oman
Publication: Journal of Construction Engineering and Management
Volume 136, Issue 5
Abstract
Change orders are usually issued to cover variations in scope of work, material quantities, design errors, and unit rate changes. This paper discusses variations in public construction projects in Oman by investigating causes of variations, studying their effects on the project, identifying the beneficial parties, and suggesting remedies to alleviate related problems. Tasks included an analysis of four actual case studies and conducting a field survey via a questionnaire. It was determined that the client’s additional works and modifications to design were the most important factors causing change orders, followed by the nonavailability of construction manuals and procedures. The most important effects of change orders on the project were found to be the schedule delays, disputes, and cost overruns. The contractor was found to be the party most benefiting from the change orders followed by the consultant and then the client. A set of remedial actions were suggested and respondents viewed that the revision of registration of consulting offices would be the most important action followed by establishing standard documents for design procedures and building a national database about soil conditions and services.
Get full access to this article
View all available purchase options and get full access to this article.
References
Acharya N. K., Lee Y. D., and Im H. M. (2006). “Conflicting factors in construction projects: Korean perspective.” Eng., Construct., Archit. Manage., 13(6), 543–566.
Akpan, O. P., and Igwe, O. (2001). “Methodology for determining price variation in project execution.” J. Constr. Eng. Manage., 127(5), 367–373.
Al-Momani A. H. (2000). “Construction delay: A quantitative analysis.” Int. J. Proj. Manage., 18(1), 51–59.
Arun, C., and Rao, B. N. (2007). “Knowledge based decision support tool for duration and cost overrun analysis of highway construction projects.” J. Inst. Eng. (India), Part AG, 88, 27–33.
Assaf, S. A., and Al-Hejji, A. (2006). “Causes of delay in large construction projects.” Int. J. Proj. Manage., 24, 349–357.
Chan, D. W. M., and Kumaraswamy, M. M. (1997). “A comparative study of causes of time overruns in Hong Kong construction projects.” Int. J. Proj. Manage., 15(1), 55–63.
Chen J. H., and Hsu S. C. (2007). “Hybrid ANN-CBR model for disputed change orders in construction projects.” Autom. Constr., 17, 56–64.
Goudreau, H. (2001). “The five key elements of a construction contract—Forget them and you are in trouble.” ⟨www.hgassociates.com/articlecontracts.html⟩ (Feb. 18, 2010).
Hanna, A. S., Camlic, R., Peterson, P. A., and Nordheim, E. V. (2002). “Quantitative definition of project impacted by change orders.” J. Constr. Eng. Manage., 128(1), 57–64.
Ibbs, C. W. (1997). “Quantitative impacts of project change: Size issue.” J. Constr. Eng. Manage., 123(3), 308–311.
Kaming, P., Olomlaiye, P., Holt, G., and Harris, F. (1997). “Factors influencing construction time and cost overruns on high-rise projects in Indonesia.” Constr. Manage. Econom., 15, 83–94.
Lee J. K. (2008). “Cost overrun and cause in Korean social overhead capital projects: Roads, rails, airports and ports.” J. Urban Plann. Dev., 134(2), 59–62.
Memon, Z. A. (2004). “Remedial measure for delays at construction stage.” J. Mehran Univ. (Eng. Technol.), 23(1), 9–20.
Ministry of Finance, Oman. (1999). Standard document for building and civil engineering works, 3rd Ed., Ministry of Finance, Muscat.
Perkins, R. A. (2007). “Sources of changes in design/build contracts for a governmental owner, management of engineering and technology.” Portland International Centre for Publication, 5–9, 2148–2153.
Sambasivan, M., and Soon, Y. W. (2007). “Causes and effects of delays in Malaysian construction industry.” Int. J. Proj. Manage., 25, 517–526.
Serag, E., and Oloufa, A. (2007). “Change orders impact on project cost, AC2007–3039.” American Society for Engineering Education, ⟨www.icee.usm.edu/ICEE/conferences/asee2007/papers/3039_CHANGE_ORDERS_IMPACT_ON_pROJECT_COST.pdf⟩ (Aug. 16, 2008).
Serag, E., Oloufa, A., and Malone, L. (2008). “Reconciliation of owner and contractor views in heavy construction projects.” J. Profl. Issues Eng. Educ. Pract., 134(1), 128–137.
Sultan Qaboos Camp. (2005). Omanization seminar, Ibri, Oman.
Wu C., Hsieh T. and Cheng W. (2005). “Statistical analysis of causes for design change in highway construction in Taiwan.” Int. J. Proj. Manage., 23, 554–563.
Information & Authors
Information
Published In
Copyright
© 2010 ASCE.
History
Received: Dec 19, 2008
Accepted: Sep 18, 2009
Published online: Sep 19, 2009
Published in print: May 2010
Authors
Metrics & Citations
Metrics
Citations
Download citation
If you have the appropriate software installed, you can download article citation data to the citation manager of your choice. Simply select your manager software from the list below and click Download.