Pipelines 2020
Changes in Trenchless Construction Contracts and the Protection Afforded to Subcontractors under Contract Law
Publication: Pipelines 2020
ABSTRACT
Changes are common in construction projects and are primarily due to design changes or owner-directed changes. On average, 35% of projects experience at least one major change during construction. Changes can occur at any stage of the construction process, can be caused by a range of factors, and can have far reaching implications on project cost and schedule. Since most trenchless companies generally operate as subcontractors on construction projects, it is important to understand how these changes impact subcontract performance. Through an extensive review of literature and some court cases in the U.S., this paper analyzes some of the risks and protections afforded to trenchless subcontractors under contract law. A significant finding is that the prime contractor is not required by law to subcontract with the listed subcontractor if the work to be subcontracted has been changed substantially or deleted by a change order. Another finding is that a subcontractor can use the third-party beneficiary theory to recover damages from the owner even in the absence of contractual privity. Finally, subcontractors must be wary of exculpatory clauses in the contract that may undercut their efforts to recover damages. It is expedient and imperative for trenchless subcontractors to be aware of these legal provisions and how they can leverage them to protect their companies from loss.
Get full access to this article
View all available purchase options and get full access to this chapter.
REFERENCES
Affholder, Inc., v. Mitchell Engineering, Inc., A114943 (Court of Appeal, First District, Division 3, California. July 18, 2007).
Calvert, C. A., & Ingwalson, C. F. (1998). Pass Through Claims and Liquidation Agreements. The Construction Lawyer, 29.
Cantwell, E. K. (2012, June 26). Changes and Change Orders. Construction Contract Clause Digest, pp. 9–13.
Civitello, J. A. (1987). Contractor’s Guide to Change Orders: The Art of Finding, Pricing and Getting Paid for Contract Changes and the Damages They Cause. Eaglewood Cliffs: Prentice-Hall, Inc.
Clough, R. H. (1986). Construction contracting (5th ed.). Albuquerque, New Mexico: John Wiley & Sons, Inc.
Dukellis, G. (n.d.). Pass-Through Claims and Liquidation Agreements. Retrieved from Global Construction and Infrastructure Legal Alliance: http://www.gcila.org/publications/files/pub_en_231.pdf.
Eyth, M. (2011, January 28). No Damages For Delay Clause Bars Pass-Through Claim. Retrieved from Real Property and Development Review: http://www.dwtrealpropertyreview.com/2011/01/28/no-damages-for-delay-clause-bars-pass-through-claim/.
Harper/Nielsen-Dillingham, Builders, Inc. v. United States, 05-269C (The United States Court of Federal Claims April 29, 2008).
Interstate Contracting Corporation v. City of Dallas, No. 03-0152 (Supreme Court of Texas April 23, 2003).
Joshi. (2019). Third Party Beneficiaries In Construction Litigation. Retrieved from joshi attorneys + counselors: https://www.joshiattorneys.com/Business-And-Commercial-Litigation-Topics/Third-Party-Beneficiaries-In-Construction-Litigation.shtml.
Kraftson, D. J. (2012). No-Damage-for-Delay Contract Clauses. Retrieved from kraftsoncaudle:Construction and Government Contract Law: http://www.kraftsoncaudle.com/cutsheets/NoDamageForDelayContractClauses.PDF.
Libor, M. R. (2001, December 1). Changes, Changed Conditions and Scope Changes Affecting Payment. Retrieved from Morgan Lewis: https://www.morganlewis.com/pubs/2DEB7DC9-39A7-4BC4-AC389AFD92A82B4B_Publication.pdf.
Loulakis, M. C., & McLaughlin, L. P. (2008). Government Avoids Liability on Contractor Pass-Through Claim. Civil Engineering, 88.
Lundeen Coatings Corporation v. Department of Water and Power of The City of Los Angeles, B051503 (Court of Appeals of California, Second District, Division Five. July 23, 1991).
Montoya, M., & Campbell, D. E. (2019). Construction Contracts and Law. St. Paul, MN, United States of America: West Academic Publishing.
Morrow, B. J. (2012). “Pass-Through Claims” Against Federal and State Governments – Lessonsfor Prime Contractors, Subcontractors, Material Suppliers and Sureties. Retrieved from kraftsoncaudle:Construction and Government Contract Law: http://www.kraftsoncaudle.com/cutsheets/PassThroughClaimsAgainstFederalandState.PDF.
Purdy, M. E. (2014, March 31). Construction Change Orders. Retrieved from MRSC: http://www.mrsc.org/subjects/pubworks/sourcebook/documents/app%20h3%20-%20change%20orders%20-%20mike%20purdy.pdf.
Rath, T. F. (2014, January 22). Lessons learned from 71 years of the Severin doctrine. Retrieved from HuschBlackwell: https://www.contractorsperspective.com/claims-and-disputes/lessons-learned-from-71-years-of-the-severin-doctrine/.
Robert Duncan v. Lauretta Cannon, 1-88-3007 (Appellate Court of Illinois, First District, First Division. September 24, 1990).
Rossetti, K., & McKeeman, M. T. (2007). Bid Awards: Change Order Pulls Rug out From Under Tunneling Subcontractor. Cost Engineering, 49(8), 11-12. Retrieved from http://0-web.b.ebscohost.com.maurice.bgsu.edu/ehost/detail?vid=46&sid=a64284ef-4067-48d8-a2c0-3a4e05e72f50%40sessionmgr110&hid=119&bdata=JnNpdGU9ZWhvc3QtbGl2ZSZzY29wZT1zaXRl#db=bth&AN=26492588.
Schaufelberger, J. E., & Holm, L. (2002). Management of Construction Projects: A Constructor’s Perspective. Upper Saddle River: Prentice Hall.
Shaw Constructors, Inc.,v. ICF Kaiser Engineers, Inc., and PCS Nitrogen Fertilizer, L.P. et al., 02-30183 (United States Court of Appeals for the Fifth Circuit January 24, 2005).
Smith, Currie & Hancock, LLP. (2015). Smith, Currie & Hancock’s Common Sense Construction Law: A Practical Guide for the Construction Professional. (J. T. Kelleher, J. M. Mastin, & R. G. Robey, Eds.) Hoboken, New Jersey, United States of America: John Wiley & Sons, Inc.
Information & Authors
Information
Published In
Pipelines 2020
Pages: 372 - 381
Editors: J. Felipe Pulido, OBG, Part of Ramboll and Mark Poppe, Brown and Caldwell
ISBN (Online): 978-0-7844-8320-6
Copyright
© 2020 American Society of Civil Engineers.
History
Published online: Aug 6, 2020
Published in print: Aug 6, 2020
Authors
Metrics & Citations
Metrics
Citations
Download citation
If you have the appropriate software installed, you can download article citation data to the citation manager of your choice. Simply select your manager software from the list below and click Download.