TECHNICAL PAPERS
Oct 1, 2004

United Kingdom Construction Claims: Views of Professionals

This article has a reply.
VIEW THE REPLY
This article has a reply.
VIEW THE REPLY
Publication: Journal of Construction Engineering and Management
Volume 130, Issue 5

Abstract

A novel approach has been used to attempt to understand how contractors justify their claims on construction contracts and how contract administrators are likely to assess them. This is done by encapsulating particular claim types into scenarios and interviewing not only contractors and contract administrators, but also claims consultants, to hear their views on how the situations represented by the scenarios should be resolved. In this paper, four areas of general uncertainty surrounding claims in the United Kingdom are described and the results of the survey on these four areas are reported. The concerns addressed are: the treatment of exceptionally adverse weather; dealing with early completion schedules; quantification of the prolongation costs associated with an approved extension of time; and concurrent delays. The results show some good agreement, particularly on the problems of dealing with exceptionally adverse weather and with some aspects of concurrent delay assessment. Although the consensus was not so clear on the other two issues, there was a majority view that should give professionals working in this area greater confidence when dealing with these problems.

Get full access to this article

View all available purchase options and get full access to this article.

References

1.
Barlow, J., and Cohen, M. ( 1996). “Implementing partnering: some common red-herrings in the literature.” Proc., ESRC/EPSRC Workshop on Partnering in Construction, Univ. of Salford, Salford, U.K.
2.
Beer, M., Eisenstat, R. A., and Spector, B. (1990). “Why change programs don’t produce change.” Harvard Bus. Rev., Nov./Dec., 158–66.
3.
Bresnen, M. (1996). “An organizational perspective on changing buyer-supplier relations: A critical review of the evidence.” Organization, 3(1), 121–46.
4.
Committee of Public Accounts (CPA). ( 1993). “Contracting for roads, Session 1992–93.” 43rd Rep., House of Commons, London.
5.
Egan, J. ( 1998). “Rethinking construction.” Rep. of the Construction Task Force to the Deputy Prime Minister, DETR, U.K.
6.
Institution of Civil Engineers. (ICE). ( 1973). Conditions of contract, 5th Ed., Thomas Telford, London.
7.
Institution of Civil Engineers. (ICE). ( 1991). Conditions of contract, 6th Ed., Thomas Telford, London.
8.
Institution of Civil Engineers. (ICE). ( 1995). The engineering and construction contract: An NEC document, 2nd Ed., Thomas Telford, London.
9.
Joint Contracts Tribunal. (JCT). ( 1980). Joint Contracts Tribunal standard form of building contract, JCT80, RIBA, London.
10.
Kraiem, Z. M., and Diekmann, J. E. (1987). “Concurrent delays in construction projects.” J. Constr. Eng. Manage., 113(4), 591–602.
11.
Latham, M. ( 1994). “Constructing the team.” Final Rep. of the Government/Industry Review of Procurement and Contractual Arrangements in the UK Construction Industry, HMSO, London.
12.
National Audit Office. ( 1992). “Department of transport contracting for roads.” Rep. Prepared for the Comptroller and Auditor General, HMSO, London.
13.
New Civil Engineer (NCE). ( 1999). Consultants file, Emap Business Communications, London.
14.
Rubin, R. A., Guy, S. D., Maevis, A. C., and Fairweather, V. ( 1983). Construction claims, analysis, presentation and defense, Van Nostrand‐Reinhold, London.
15.
Scott, S. (1997). “Delay claims in U.K. contracts.” J. Constr. Eng. Manage., 123(3), 238–244.
16.
New Civil Engineer (NCE). ( 1999). Contractors file, Emap Business Communications, London.

Information & Authors

Information

Published In

Go to Journal of Construction Engineering and Management
Journal of Construction Engineering and Management
Volume 130Issue 5October 2004
Pages: 734 - 741

History

Published online: Oct 1, 2004
Published in print: Oct 2004

Permissions

Request permissions for this article.

Authors

Affiliations

Steve Scott
Dept. of Civil Engineering, Univ. of Newcastle upon Tyne, Claremont Rd., Newcastle upon Tyne NE1 7RU, U.K. (corresponding author). E-mail: [email protected]
Richard Anthony Harris
Dept. of Civil Engineering, Univ. of Newcastle upon Tyne, Claremont Rd., Newcastle upon Tyne NE1 7RU, U.K.

Metrics & Citations

Metrics

Citations

Download citation

If you have the appropriate software installed, you can download article citation data to the citation manager of your choice. Simply select your manager software from the list below and click Download.

Cited by

View Options

Get Access

Access content

Please select your options to get access

Log in/Register Log in via your institution (Shibboleth)
ASCE Members: Please log in to see member pricing

Purchase

Save for later Information on ASCE Library Cards
ASCE Library Cards let you download journal articles, proceedings papers, and available book chapters across the entire ASCE Library platform. ASCE Library Cards remain active for 24 months or until all downloads are used. Note: This content will be debited as one download at time of checkout.

Terms of Use: ASCE Library Cards are for individual, personal use only. Reselling, republishing, or forwarding the materials to libraries or reading rooms is prohibited.
ASCE Library Card (5 downloads)
$105.00
Add to cart
ASCE Library Card (20 downloads)
$280.00
Add to cart
Buy Single Article
$35.00
Add to cart

Get Access

Access content

Please select your options to get access

Log in/Register Log in via your institution (Shibboleth)
ASCE Members: Please log in to see member pricing

Purchase

Save for later Information on ASCE Library Cards
ASCE Library Cards let you download journal articles, proceedings papers, and available book chapters across the entire ASCE Library platform. ASCE Library Cards remain active for 24 months or until all downloads are used. Note: This content will be debited as one download at time of checkout.

Terms of Use: ASCE Library Cards are for individual, personal use only. Reselling, republishing, or forwarding the materials to libraries or reading rooms is prohibited.
ASCE Library Card (5 downloads)
$105.00
Add to cart
ASCE Library Card (20 downloads)
$280.00
Add to cart
Buy Single Article
$35.00
Add to cart

Media

Figures

Other

Tables

Share

Share

Copy the content Link

Share with email

Email a colleague

Share